Loading...
HomeMy WebLinkAbout18-121 - Comcast Cable Communications Management - Memorandum of Agreement for 53rd Avenue South (S 144th Street to South 137th Street)18-121 Council Approval 7/16/18 MEMORANDUM OF AGREEMENT Between the City of Tukwila and Comcast for the 53rd Avenue South Project - (S 137th Street to S 144th) THIS MEMORANDUM OF AGREEMENT (this "Agreement"), is entered into as of the date last signed below between the City of Tukwila, a Washington municipal corporation ("City"), and Comcast Cable Communications Management, LLC, a Delaware limited liability company ("Comcast") (each a -Party- and collectively the "Parties"), and sets forth the tetitis and work guidelines for the planning, coordination, and relocation of certain utilities made necessary by the Project described below. RECITALS WHEREAS, the City is making right-of-way improvements to 53rd Ave S between S 137th St and S 144' St (the "Project"); and WHEREAS, the City has determined that the Project is a public project and will necessitate the relocation and new construction of Comcast utility infrastructure located within the boundaries of the Project; and WHEREAS, Comcast currently maintains and operates its utility infrastructure within the public rights -of -way of City (including 53rd Ave. S) under a franchise grant given to Comcast; and WHEREAS, Comcast acknowledges that the City has given notice to Comcast and third party users of the necessity to remove existing aerial utility infrastructure along 53rd Ave; and WHEREAS, relocation requires trenching within the right-of-way and the Parties recognize the efficiencies of entering into an agreement whereby one trench will be dug for all of the affected utilities to relocate their facilities; and WHEREAS, Comcast and the City intend for this Agreement to provide a process for cooperation and coordination in the design, estimating, scheduling, construction, and payment for, the utility undergrounding Work (hereinafter defined) in an efficient and cost-effective manner. NOW THEREFORE, in consideration of the mutual benefits to be provided the Parties through this Agreement, it is hereby agreed as follows: AGREEMENT To facilitate construction of a joint trench, the Parties agree as follows: JOINT TRENCH AGREEMENT— Page 1 of 11 (between City of Tukwila and Comcast Re: 53Ave S. project) (June 28, 2018) SCOPE OF WORK The City of Tukwila will advertise for construction bids and enter into a contract with a Contractor for the construction of a joint utility trench which shall include Comcast, Century Link, and SCL power facilities. This joint utility trench will be placed within the northbound lane of 53rd Ave. S. between S. 137th and S. 144'1' St. in accordance with the Project plans. 2. CONTRACTOR REQUIREMENTS The independent contractor hired by the City to perforni this Work shall be referred to as "Contractor" in this Agreement. The Contractor, pursuant to a contract with the City, shall excavate the trench and install Comcast, Century Link, and SCL power facilities, accommodate and coordinate the installation of Comcast facilities, install the bedding material, backfill and compact the trench, and perform any restoration required by the City, all to be performed in a good and workmanlike manner consistent with industry standards (the "Work"). The City represents that any such contract shall further require of Contractor that the Work be conducted in conformity with (i) the applicable procedures and requirements of the Parties as described herein and of those that own or have jurisdiction over the rights of way in which the Work is to be performed; (ii) all applicable laws, ordinances and regulations of any governmental authority, and; (iii) all applicable terms and provisions of the National Electric Safety Code, as may be amended, supplemented or replaced from time to time, including but not limited to those pertaining to protection and separation of conductors buried in earth. 3. RESPONSIBILITY OF THE PARTIES A. Drawings. Comcast shall provide engineering drawings, specifications, construction standards, estimated material quantities, and cost estimates to the City for the underground relocation of Comcast's facilities. The drawings shall show in detail the location and elevation of the Comcast conduits, trench, and vaults, and shall include a general traffic control plan for activities not associated with installation of facilities within the Contractor controlled open trench area. B. Installation. Comcast shall furnish its conduit for installation by Contractor in the City provided trench and shall furnish and deliver to the site all vaults for installation by Contractor in a timely manner as outlined in subsection 3.D. Comcast shall schedule all deliveries and work so as not to delay Contractor. All rights, title and interest in the facilities and associated equipment shall at all times remain with Comcast. The Parties hereto acknowledge and agree that Comcast shall in no event be required to remove their respective, affected facilities, prior to completion of their underground facilities, in accordance with this Agreement, as long as said installation is completed in conformity with this Agreement. JOINT TRENCH AGREEMENT- Page 2 of 11 (June 28, 2018) (between City of Tukwila and Comcast Re: 53' Ave S. project) C. Traffic Control. Contractor shall perform all traffic control associated with installation of facilities within the Contractor controlled open trench area. Comcast shall be responsible for providing traffic control during installation of facilities not associated with or in the controlled open trench area. D. Comcast Coordination. Contractor will excavate for and place Comcast vaults in the trench including bedding and backfill. Comcast shall maintain continued coordination with Contractor regarding the installation of Comcast's facilities. This coordination shall include but not be limited to the following: . Timing of when and where materials will be delivered on -site. 2. Contractor shall provide Comcast weekly scheduling notifications. 3. Comcast shall coordinate closely with Contractor to provide all necessary materials in a timely manner. E. Surveys. The City will provide the survey for the location of the trench and vaults. 4. COMPENSATION A. Trench costs. Comcast agrees to pay the City a portion of the trench costs, including trench bedding and backfill, commensurate with its proportionate share of trench usage as shown in Exhibit A attached hereto and incorporated by this reference. Preliminary costs will be agreed upon prior to construction based on an estimate from the bid accepted by the City. Costs will be finalized after completion of construction to account for actual construction costs and will be subject to final review and approval by Comcast. B. Survey. Comcast agrees to pay the reasonable costs for the City surveyor's time to provide vault locations and elevations and any other survey that may be required to locate and place Comcast facilities. C. Traffic Control. Comcast agrees to pay the City its proportionate share of traffic control costs related to the Contractor controlled open trench areas where Comcast facilities are present. The proportionate share shall be based on trench usage as shown in Exhibit A. Comcast shall be responsible to pay for all traffic control during the installation of Comcast facilities, not associated with the controlled open trench area. D. Additional Expenses. Comcast agrees to pay its proportionate share of mutually agreed additional expenses incurred due to all of Comcast's approved change requests requiring additional trench depth or width and for unforeseen conditions, including but not limited to JOINT TRENCH AGREEMENT- Page 3 of 11 (between City of Tukwila and Comcast Re: 53' Ave S. project) (June 28, 2018) dewatering for ground water. Comcast will not pay for any share of additional expenses incurred due solely to approved change requests from other private utilities and/or the City. E. Claims by Contractor. Comcast agrees to pay the entire cost of any reasonable and documented claims made by Contractor that are caused by Comcast. These claims may include delays caused by the installation by Comcast of its facilities, delays caused by Comcast providing its materials, or any other conflicts between Contractor and Comcast. These claims must be verifiable or substantiated claims. F. Vaults. Comcast agrees to pay for the excavation, site preparation, and installation for its vaults, including bedding and backfill, separately and in addition to any survey costs and trench costs discussed above. These additional costs shall be preliminarily determined from the bid price accepted by the City. The cost to excavate for and install Comcast's vaults will be finalized after completion of construction to account for actual construction costs and will be subject to final review and approval by Comcast. G. Mvoice. The estimated share of Comcast's cost related to the Project, as described in Exhibit A, is $97,450.91 including applicable sales tax (the "Estimated Comcast Cost Share"). The Estimated Comcast Cost Share is based on the City's engineering construction estimates of the Project and is subject to change based upon final bid review, award of all relevant Work and change orders. The actual costs charged to Comcast will be determined based on itemized Contractor invoices and payment requests from Contractor for actual Work performed or completed and will be subject to final review and approval by Comcast. City will invoice Comcast by itemized monthly invoices with backup documentation, which shall include relevant invoices and payment requests, for Project costs to Comcast. Comcast agrees to pay the City within sixty (60) days of receipt of a correct invoice from the City for amounts that Contractor has invoiced the City for work that has been completed by the Contractor and approved by COMCAST, and which Comcast has agreed to pay under this Agreement. H. Defective or Unauthorized Work. City agrees that its agreement with Contractor will require Contractor to comply with the Comcast requirements as set forth in the plans and specifications approved by Comcast; provided however, that under no circumstance shall Comcast or its employees, agents or contractors be responsible for or authorized to give direction to or direct work by Contractor. City further agrees that per the tethis of the agreement between the City and Contractor, Comcast reserves the right to withhold payment from the City for any defective or unauthorized work performed by Contractor. Defective or unauthorized work includes, without limitation, work and materials that do not conform to the requirements of this Agreement, and extra work and materials furnished without Comcast's approval. If for any reason it is necessary to satisfactorily complete any portion of the Work, Comcast may complete the Work using its own means, and the City shall be responsible for any Additional Costs incurred by Comcast hereunder. "Additional Costs" shall mean all reasonable costs, including legal costs and attorney fees, incurred by the parties beyond the price included in the bid accepted by the City. Comcast further reserves the right to offset the cost to complete the Work, including any additional costs, from any and all amounts due or to become due the Contractor. JOINT TRENCH AGREEMENT— Page 4 of 11 (June 28, 2018) (between City of Tukwila and Comcast Re: 5.31d Ave S. project) 1. Final Payment/Waiver of Claims. The making of final payment by the Parties shall constitute a waiver of claims by the City and Contractor, except those previously and properly made and identified by the City and Contractor as unsettled at the time request for final payment is made. 5. CHANGES. Comcast shall submit any changes requested to be performed by Contractor to the City. The City shall submit this to Contractor; obtain a price from Contractor to perform the Work, and notify Comcast of this price. Comcast shall then have 48 hours from the time it receives the price from the City, within which to respond. If Comcast chooses not to accept Contractor's price then this Work shall only be performed by Comcast according to a mutually agreed upon schedule with Contractor so as not to cause unreasonable delay to Contractor. Any costs associated with work completed outside of the mutually approved plans and specifications and approved amendments thereto without Comcast approval will be City's responsibility. 6. INDEMNIFICATION; LIENS AND ENCUMBRANCES. City shall defend, indemnify and hold Comcast and its directors, officers, officials, employees, representatives and agents harmless from and against any and all claims, injuries, damages, losses, harm, liabilities, suits, costs and expenses (including, but not limited to, reasonable attorney fees), caused by or arising out of any Work performed by the City, Contractor and each of their respective directors, officers, officials, employees, contractors, subcontractors, representatives and agents in their performance under this Agreement, except for injuries and damages caused by the negligence or willful misconduct of Comcast. During the performance of such activities, City's employees or contractors shall at all times remain employees or contractors, respectively, of City. Comcast shall defend, indemnify and hold City and its officers, officials, employees, representatives and agents harmless from and against any and all claims, injuries, damages, losses, harm, liabilities, suits, costs and expenses (including, but not limited to, reasonable attorney fees), caused by or arising out of any Work performed by Comcast in its performance under this Agreement, except for injuries and damages caused by the negligence or willful misconduct of City or Contractor. During the performance of such activities, Comcast's employees or contractors shall at all times remain employees or contractors, respectively, of Comcast. Should a court of competent jurisdiction determine that this Agreement is subject to RCW 4.24.115, then, in the event of liability for damages arising out of bodily injury to persons or damages to property caused by or resulting from the concurrent negligence of the Parties, their officials, employees and agents, a Party's liability hereunder shall be only to the extent of the JOINT TRENCH AGREEMENT- Page 5 of 11 (June 28, 2018) (between City (y.Tukwila and Comcast Re: 53' Ave S. project) Party's negligence. The provisions of this section shall survive the expiration or termination of this Agreement. No Party, directly or indirectly, shall create or impose any lien on the property of another, or on the rights or title relating thereto, or any interest therein, or in this Agreement. Each Party shall promptly, at its own expense, take such action as may be necessary to duly discharge any lien created by it on the property of another. EXCEPT AS EXPRESSLY PROVIDED HEREIN, NEITHER PARTY SHALL BE LIABLE TO THE OTHER FOR ANY INCIDENTAL, INDIRECT, SPECIAL OR CONSEQUENTIAL DAMAGES OF ANY KIND, INCLUDING BUT NOT LIMITED TO ANY LOSS OF USE, LOSS OF BUSINESS OR LOSS OF PROFIT. 7. INSURANCE. City shall contractually require that Contractor maintain in full force and effect at its own cost insurance of the types and in the amounts described below against claims for injuries to persons or damage to property which may arise from or in connection with the performance of the Work by Contractor, its agents, representative, employees, sub consultants or subcontractors: A. Commercial General Liability insurance with limits of no less than three million dollars ($3,000,000.00) per occurrence and five million dollars ($3,000,000.00) general aggregate. Coverage shall be at least as broad as that provided by ISO CG 00 01 1/96 or its equivalent and include severability of interests. Coverage shall include, but not be limited to: blanket contractual, Products/Completed operations/broad form property damage; explosion, collapse and underground (XCU); and employers liability. Such insurance shall name the City, Comcast, and their respective officers, officials and employees as additional insureds per ISO CG 2026 or its equivalent. There shall be a waiver of subrogation and rights of recovery against the City, Comcast, and their respective officers, officials and employees. Coverage shall apply as to claims between insureds on the policy, if applicable. Coverage may take the form of a primary layer and a secondary or umbrella layer, but the combination of layers must equal $3,000,000 at a minimum. B. Commercial Automobile Liability insurance with minimum combined single limits of one million dollars ($1,000,000.00) each occurrence with respect to each of Contractor's owned, hired and non -owned vehicles assigned to or used in the operation of this contract in the City. The policy shall contain a severability of interests' provision. C. The insurance shall not be canceled or materially changed so as to be out of compliance with these requirements without thirty (30) days' written notice first provided to the City, via certified mail, and ten (10) days' notice for nonpayment of premium. If the insurance is canceled or materially altered so as to be out of compliance with the requirements of JOINT TRENCH AGREEMENT— Page 6 of 11 (June 28, 2018) (between City of Tukwila and Comcast Re: 53rd Ave S. project) this subsection within the term of this contract, Contractor shall provide a replacement policy. Contractor agrees to maintain continuous uninterrupted insurance coverage, in at least the amounts required, for the duration of this contract. Deductibles / Certificate of Insurance Any deductible of the policies shall not in any way limit Contractor's liability to the City or to Comcast. A. Endorsements. (1) All policies shall contain, or shall be endorsed so that: (a) The City, its officers, officials, boards, commissions, employees and agents are to be covered as, and have the rights of, additional insureds with respect to liability arising out of activities perfoiiiied by, or on behalf of, Contractor under this contract; (b) Contractor's insurance coverage shall be primary insurance with respect to the City, Comcast, and their respective officers, officials, boards, commissions, employees and agents. Any insurance or self-insurance maintained by the City, Comcast, and their respective officers, officials, boards, commissions, employees and agents shall be in excess of Contractor's insurance and shall not contribute to it; and (c) Contractor's insurance shall apply separately to each insured against whom a claim is made or lawsuit is brought, except with respect to the limits of the insurer's liability. B. Acceptability of Insurers. The insurance obtained by Contractor shall be placed with insurers with a Best's rating of no less than "A VII." C. Verification of Coverage. The Contractor shall furnish the City with certificates of insurance and endorsements or a copy of the page of the policy reflecting blanket additional insured status. The certificates and endorsements for each insurance policy are to be signed by a Person authorized by that insurer to bind coverage on its behalf The certificates and endorsements for each insurance policy are to be on standard forms or such forms as are consistent with standard industry practices. 8. FRANCHISE AGREEMENT. The City and Comcast agree that as to future projects, by entering into this Agreement neither Party has waived any rights it may have under the existing franchise agreement between the City and Comcast, and the City and Comcast expressly herein reserve such rights. JOINT TRENCH AGREEMENT— Page 7 of 11 (June 28, 2018) (between City of Tukwila and Comcast Re: 53'' Ave S. project) Notwithstanding anything in this Agreement to the contrary, Comcast's participation in the joint trench activity contemplated in this Agreement, and its very participation in this Agreement, shall in no event be construed as acceptance, affirmation or ratification of the City's construction of Comcast's obligation to underground their facilities and enter into a writing pursuant to the franchise agreement, and the Parties understand and agree that the terms and conditions of this Agreement shall not be considered as a basis for future undergrounding projects that may be franchise -required. 9. MISCELLANEOUS. A. Compliance with Laws. The Parties shall comply with all federal, state and local laws, rules and regulations throughout every aspect in the performance of this Agreement. B. Nonwaiver of Breach. The failure of a Party to insist upon strict perfoli lance of any of the terms and rights contained herein, or to exercise any option herein conferred in one or more instances, shall not be constructed to be a waiver or relinquishment of those terms and rights and they shall remain in full force and effect. C. Governing Law. This Agreement shall be governed and construed in accordance with the laws of the State of Washington. If any dispute arises between the Parties or between any Party and Contractor under any of the provisions of this Agreement, resolution of that dispute shall be available only through the jurisdiction, venue and rules of the King County Superior Court, King County, Washington. D. Attorney's Fees. To the extent not inconsistent with RCW 39.04.240, in any claim or lawsuit for damages arising from the Parties' performance of this Agreement, the parties specifically understand and agree that the prevailing Party in any such action shall be entitled to its reasonable attorneys' fees and costs of suit; however, nothing in this subsection shall limit a Party's right to indemnification under Section 8 of this Agreement. E. Written Notice. All communications regarding this Agreement shall be sent to the Parties at the addresses listed on the signature page of this Agreement, unless otherwise notified. Any written notice shall become effective upon delivery, but in any event three (3) calendar days after the date of mailing by registered or certified mail, and shall be deemed sufficiently given if sent to the addressee at the address stated on this Agreement. F. Modification. No waiver, alteration, or modification of any of the provisions of this Agreement shall be binding unless in writing and signed by a duly authorized representative of each of the affected Parties. G. Severability. If any one or more sections, sub -sections, or sentences of this Agreement are held to be unconstitutional or invalid, that decision shall not affect the validity of the remaining portion of this Agreement and the remainder shall remain in full force and effect. JOINT TRENCH AGREEMENT- Page 8 of 11 (June 28, 2018) (between City of Tukwila and Comcast Re: 53 Ave S. project) H. Relationship. It is understood and agreed that no agency, employment, joint venture, co -employer or partnership is created by this Agreement. No Party hereto shall (i) have the power or authority to act for another in any manner to create obligations or debts which would be binding upon another, and; (ii) be responsible for any obligation or expense whatsoever of the other Party except as set forth herein. 1. Force Majeure. Parties shall not be deemed to be in breach of this Agreement if unable to perform their respective obligations hereunder as a result of the occurrence of an event of -force majeure," which shall include, but not be limited to, acts of God, acts of the government of the United States or of any state or political subdivision thereof, strikes, civil riots or disturbances, fire, floods, explosions, earthquakes, wind, storms, hurricanes, lightning or other similar catastrophes or other causes beyond the Parties' reasonable control. The scope of events of force majeure shall not extend to payment of money owed hereunder. J. Assignment. Neither Party shall assign this Agreement or any of its rights or obligations hereunder without the prior written consent of the other, which consent will not be unreasonably withheld or delayed. Notwithstanding the foregoing, either may assign all or part of this Agreement immediately, without the prior written consent of the other Party (a) to any entity that controls, is controlled by, or is in common control with a Party or (b) to any successor in interest to a Party or (c) if necessary to satisfy the rules, regulations and/or orders of any federal, state or local governmental agency or body. K. Entire Agreement. The written provisions and teiins of this Agreement, together with any attached Exhibits, supersede all prior verbal statements by any representative of the City, and those statements shall not be construed as forming a part of or altering in any manner this agreement. This Agreement and any attached Exhibits contain the entire Agreement between the Parties. Should any language in any Exhibit to this Agreement conflict with any language contained in this Agreement, the terms of this Agreement shall prevail. JOINT TRENCH AGREEMENT —Page 9 of 11 (June 28, 2018) (between City of Tukwila and Cornetist Re: 53rd Ave S. project) IN WITNESS WHEREOF, the Parties below have executed this Agreement. COMCAST CABLE COMMUNICATIONS MANAGEMENT, LLC DATE Ab NOTICES TO BE SENT TO: COMCAST CABLE COMMUNICATIONS MANAGEMENT, LLC Comcast Cable Communications Management, LLC Tukwila Public Works 410 Valley Ave NW, Suite 12 Bldg C Puyallup, WA 98371 Attn: Bill Walker (253) 288-7538 (Desk) (206) 255-6975 (Cell) With a copy to: Comcast Cable Communications Management, LLC 1701 JFK Boulevard Philadelphia, PA 19103 Attention: General Council 1' ,Civi Fl ,ES,Open Fi les' 0 I 77-2005 .Jo intTrenchAgreement-Comcasi -Military Road.doe CITY OF TUKWILA Print Name: 41._Lt4i-k filt/f4"'P Title: M /41?„:1- DATE 44ti vi 311 - NOTICES TO BE SENT TO: CITY OF TUKWILA 6300 Southcenter Blvd, Suite 100 Tukwila, WA 98188 Attn: David Sorensen (206) 431-3653 (Desk) (206) 402-8076 (Cell) APPROVED AS TO FORM: Tukwila City Attorney City of JOINT TRENCH AGREEMENT-- Page 10 of 11 (June 28, 2018) (between City ofTukwila and Comcast Re: 531d Ave S. project) Exhibit A Comcast Cost Share for S. 228'1' Street Joint Trench Agreement JOINT TRENCH AGREEMENT- Page 11 of 11 (June 28, 2018) (between City of Tukwila and Comcast Re: 5.3rd Ave S. project) Item Section EXHIBIT A - Comcast Cost Share Bid Tab 2/13/18 - SCI Infrastructure Schedule A- (COMCAST ITEMS) Description Qty Unit Price Total Comcast Created: KPG - 3/26/18 (KA) 53rd Ave S Project Compensation Responsibility A2 1-05 Roadway Surveying 1 LS $45,000.00 $45,000.00 $1,101.09 Highlighted Green Items/ Total Project Cost A10 1-10 Project Temporary Traffic Control 1 LS $300,000.00 $300,000.00 $7,340.57 Highlighted Green Items/ Total Project Cost Item Section Total Project SCI Cost = $ 5,953,249.60 Schedule C - Joint Utility Trench Duct Bank (COMCAST ITEMS) Description Qty Unit Price Total $8,441.66 $8,441.66 Comcast ch A SubTota Sch A Total Compensation Responsibility C1 1-04 Unexpected Site Changes 1 EST $25,000.00 $25,000,00 Only if required for approved Comcast CO's C3 8-31 Unsuitable Foundation Excavation Incl, Haul 230 CY $27.50 $6,325.00 Only if required during Comcast owned equipment installation C4 8-31 Structure Excavation Class B Incl, Haul for Joint Utility Trench 4330 CY $38.00 $164,540.00 50% SCL, 25% CTL, 25% Comcast C5 8-31 Shoring or Extra Excavation, Class B for Joint Utility Trench 20600 SF $1.00 $20,600.00 50% SCL, 25% CTL, 25% Comcast C6 8-31 Joint Utility Trench Pipe Zone Bedding, Incl. Haul - Communications 320 CY $37.00 $11,840.00 50% CTL, 50% Comcast C7 8-31 Joint Trench Backfill, Incl. Haul - Communications 1000 CY $37.00 $37,000.00 50% CTL, 50% Comcast C8 8-31 Crushed Surface Base Course - Structures 430 TON $35.00 $15,050.00 ' ., „ ' , 50% SCL, 25% CTL, 25% Comcast C13 8-31 Resolution of Utility Conflicts for Joint Utility Trench 1 EST $25,000.00 $25,000.00 Only if required for approved Comcast CO's C23 8 31 Install Conduit, 2 In. Diam, - COMCAST 2000 LF $5.25 ;/',�i� r w t Mt Comcast Furnish /City of Tukwila Trench C24 8-31 Install Conduit, 4 In. Diam, - COMCAST 6500 LF $7.30 � ��i " , a,r / Yak, r " 'TWA' Comcast Furnish /City of Tukwila Trench C27 8-31 Conduit Riser - COMCAST 8 EA $850.00 $6,800.00 Comcast Furnish /City of Tukwila Trench C29 8-31 Core Drill Existing Vault - COMCAST 2 EA $415.00 $830.00 j tIIr Comcast C40 8-31 Install Utility Structure, COMCAST 2436 Vault 1 EA $200.00 $200.00 V m )s 0 Comcast C41 8-31 Install Utility Structure, COMCAST 1419 Vault 5 EA $60.00 $300.00 ;j-' ®' ?xi re, Comcast C42 8-31 Install Utility Structure, COMCAST 3048 Vault 8 EA $330.00 $2,640.00 ij) ItNIA Comcast C43 8-31 Install Utility Structure, COMCAST 1730 Vault 6 EA $200.00 $1,20000 W! C, Egi i Comcast C44 8-31 Install Utility Structure, COMCAST Pedestal 2 EA $200.00 $400.00 Comcast Furnish and Install/COT Trench C45 8-31 Install Utility Structure, COMCAST 2436 Intercept Vault 1 EA $200.00 $200.00 1/1i 'iitI a are Comcast C46 8-31 Install Utility Structure, COMCAST 1419 Intercept Vault 1 EA $650.00 $650.00 / 2 e VI Comcast C47 8-31 Install Utility Structure, COMCAST 3x5` Intercept Vault 1 EA $430.00 $430.00 f%i,p` ijNt-1 fil Comcast C50 8-33 Install Conduit, 2 In. Diam. - COMCAST Private Service 1600 LF $7.30 $11,680.00 Comcast Furnish /City of Tukwila Trench ) .) BI#07 JUT TRENCH SECTION BREAKDOWN $80,917.50 Sch C Su Iota Washington State Sales Tax (10%) $8,091.75 $89,009.25 Sch C Total Grand Total $97,450.91 Tukwila will invoice Comcast this amount* 'finalized after completion of construction to account for actual construction costs. Assumptions: All work above within ROW except Bid Item C50. All service conversion trenching and conduit installation are City Responsibility outside ROW. Comcast responsible for pulling their cable ,hook-ups, connections, and removal of existing equipment in and outside of ROW.